Last Updated: 6/11/2025

Welcome to Shell Enterprises. These Terms and Conditions (“Terms”) govern your access to and use of our services, website, and any related interactions with Shell Enterprises. By accessing or using our services, you agree to be bound by these Terms.

1. Company Information

Shell Enterprises
Address: B-15, Sector 9, Noida
Phone:+91 9990630789
Email: Enquiry@shellenterprises.in

2. Services Offered

Shell Enterprises specializes in the design, manufacturing, and installation of modular kitchens, wardrobes, and interior storage solutions. All services are offered subject to site inspection and final design approval.

3. Consultation & Site Visit

  • A consultation or site visit can be scheduled via our WhatsApp, website, or phone.
  • Initial consultation may be complimentary, but detailed design planning and site measurements may incur a nominal fee, refundable upon project confirmation.

4. Quotations and Payments

  • All quotations are valid for 15 days from the date issued unless otherwise mentioned.
  • Project execution will commence only after signing of agreement and advance payment (typically 50% of total cost).
  • The remaining balance must be paid as per the milestone schedule outlined in the agreement.
  • Payments once made are non-refundable after material procurement begins.

5. Project Timeline

  • Project timelines are estimates and may vary due to material availability, client feedback delays, or unforeseen site conditions.
  • Shell Enterprises will not be liable for delays caused by third parties, natural calamities, or force majeure events.

6. Material & Design Changes

  • Once the final design is approved and materials are procured, changes may incur additional charges and extend the project timeline.
  • Shell Enterprises reserves the right to substitute materials of equal quality if original options are unavailable.

7. Warranty & Maintenance

  • Our modular kitchen products come with a 15-year warranty (exact term based on product/material chosen).
  • The warranty covers manufacturing defects only. It does not cover damages caused by misuse, water leakage, pest infestation, or lack of maintenance.
  • Periodic maintenance is the client’s responsibility unless otherwise agreed in a maintenance contract.

8. Client Responsibilities

  • Clients must ensure clear access to the site and provide water, electricity, and storage for materials during the project.
  • Any structural changes required (e.g., plumbing, electrical) will be handled separately or via a third-party contractor at additional cost.

9. Use of Images and Testimonials

  • Shell Enterprises reserves the right to use completed project images, videos, and client testimonials for marketing purposes unless explicitly denied in writing by the client.

10. Limitation of Liability

  • Shell Enterprises shall not be held liable for any indirect, incidental, or consequential damages arising out of or related to the use of our services.
  • In any case, our liability is limited to the total value of the contract signed with the client.

11. Intellectual Property

  • All design concepts, plans, and content shared with the client remain the intellectual property of Shell Enterprises until full payment is made.

12. Dispute Resolution

  • In case of any dispute, both parties agree to attempt an amicable resolution first.
  • If unresolved, the matter shall be subject to the jurisdiction of the courts located in Noida, Uttar Pradesh.

13. Modifications to Terms

  • Shell Enterprises reserves the right to update these Terms at any time. Clients will be notified of significant changes via email or website updates.

For any queries regarding these Terms and Conditions, feel free to contact us at:
📧 Enquiry@shellenterprises.in 📞 +91 9990630789